1937_CODE_OF_CIVIL_PROCEDURE_ORDINANCE — Page 197

HK Historical Laws 香港歷史法例 All AI Reviewed

Series Prev Next Source

CODE OF CIVIL PROCEDURE.

No. 3 of 1901.

891

FORM NO. 17.

[s. 163.] R.S.C., App. E, Sec. II.

Counterclaim.

Action No. of 19

IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION.

Between A.B., Plaintiff, and C.D., Defendant.

Counterclaim.

The defendant says that-

1. The contract mentioned in the statement of claim herein contained a clause whereby it was provided that the plaintiff should complete the works by the 31st March, 1909, or in default pay to the defendant $10 a day for every subsequent day during which the works should remain unfinished, and they so remained unfinished for 61 days to the 31st May, 1909.

The defendant counterclaims $610.

(Signed)

FORM No. 18.

Reply.

[s. 168.] R.S.C., App. E, Sec. II.

Action No. of 19

IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION.

Between A.B., Plaintiff, and C.D., Defendant. Reply.

issue.

The plaintiff says that-

1. As to the first paragraph of the statement of defence, he joins.

2. As to the second paragraph thereof, he accepts the $200 in satisfaction.

The plaintiff as to the counterclaim says that-

3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.

Edit History

2026-05-03 13:58:22 · NVIDIA / meta/llama-4-maverick-17b-128e-instruct

Live

View comparison

AI Proofread

CODE OF CIVIL PROCEDURE. No. 3 of 1901. 891 FORM NO. 17. [s. 163.] R.S.C., App. E, Sec. II. Counterclaim. Action No. of 19 IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION. Between A.B., Plaintiff, and C.D., Defendant. Counterclaim. The defendant says that- 1. The contract mentioned in the statement of claim herein contained a clause whereby it was provided that the plaintiff should complete the works by the 31st March, 1909, or in default pay to the defendant $10 a day for every subsequent day during which the works should remain unfinished, and they so remained unfinished for 61 days to the 31st May, 1909. The defendant counterclaims $610. (Signed) FORM No. 18. Reply. [s. 168.] R.S.C., App. E, Sec. II. Action No. of 19 IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION. Between A.B., Plaintiff, and C.D., Defendant. Reply. issue. The plaintiff says that- 1. As to the first paragraph of the statement of defence, he joins. 2. As to the second paragraph thereof, he accepts the $200 in satisfaction. The plaintiff as to the counterclaim says that- 3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.

Baseline (Original)

CODE OF CIVIL PROCEDURE. No. 3 of 1901. 891 FORM NO. 17. [8. 163.] R.S.C., App. E, Counterclaim. Sec. II. Action No. of 19 IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION. Between A.B., Plaintiff, and C.D., Defendant. Counterclaim. The defendant says that- 1. The contract mentioned in the statement of claim herein con- tained a clause whereby it was provided that the plaintiff should complete the works by the 31st March, 1909, or in default pay to the defendant $10 a day for every subsequent day during which the works should remain unfinished, and they so remained unfinished for 61 days to the 31st May, 1909. The defendant counterclaims $610. (Signed) FORM No. 18. Reply. [s. 168.] R.S.C.. App. E, Sec. II. Action No. of 19 IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION. Between A.B., Plaintiff, and C.D., Defendant. Reply. issue. The plaintiff says that- 1. As to the first paragraph of the statement of defence, he joins. 2. As to the second paragraph thereof, he accepts the $200 in satisfaction. The plaintiff as to the counterclaim says that- 3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.

2026-05-03 13:58:22 · Baseline

View content

CODE OF CIVIL PROCEDURE.

No. 3 of 1901.

891

FORM NO. 17.

[8. 163.] R.S.C.,

App. E,

Counterclaim.

Sec. II.

Action No.

of 19

IN THE SUPREME COURT OF HONG KONG,

ORIGINAL JURISDICTION.

Between A.B., Plaintiff,

and

C.D., Defendant.

Counterclaim.

The defendant says that-

1. The contract mentioned in the statement of claim herein con- tained a clause whereby it was provided that the plaintiff should complete the works by the 31st March, 1909, or in default pay to the defendant $10 a day for every subsequent day during which the works should remain unfinished, and they so remained unfinished for 61 days to the 31st May, 1909.

The defendant counterclaims $610.

(Signed)

FORM No. 18.

Reply.

[s. 168.] R.S.C..

App. E, Sec. II.

Action No.

of 19

IN THE SUPREME COURT OF HONG KONG,

ORIGINAL JURISDICTION.

Between A.B., Plaintiff,

and

C.D., Defendant. Reply.

issue.

The plaintiff says that-

1. As to the first paragraph of the statement of defence, he joins.

2. As to the second paragraph thereof, he accepts the $200 in satisfaction.

The plaintiff as to the counterclaim says that-

3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.

1937_CODE_OF_CIVIL_PROCEDURE_ORDINANCE — Page 197

Edit History

Comments

Private Research Note