CODE OF CIVIL PROCEDURE.
No. 3 of 1901.
891
FORM NO. 17.
[s. 163.] R.S.C., App. E, Sec. II.
Counterclaim.
Action No. of 19
IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION.
Between A.B., Plaintiff, and C.D., Defendant.
Counterclaim.
The defendant says that-
1. The contract mentioned in the statement of claim herein contained a clause whereby it was provided that the plaintiff should complete the works by the 31st March, 1909, or in default pay to the defendant $10 a day for every subsequent day during which the works should remain unfinished, and they so remained unfinished for 61 days to the 31st May, 1909.
The defendant counterclaims $610.
(Signed)
FORM No. 18.
Reply.
[s. 168.] R.S.C., App. E, Sec. II.
Action No. of 19
IN THE SUPREME COURT OF HONG KONG, ORIGINAL JURISDICTION.
Between A.B., Plaintiff, and C.D., Defendant. Reply.
issue.
The plaintiff says that-
1. As to the first paragraph of the statement of defence, he joins.
2. As to the second paragraph thereof, he accepts the $200 in satisfaction.
The plaintiff as to the counterclaim says that-
3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.