806
No. 3.]
Section 168. App. E, Sec, II.
THE ORDINANCES OF HONGKONG [A.D. 1901]
FORM No. 18. Reply.
Action No. of 19
IN THE SUPREME Court of Hongkong,
ORIGINAL JURISDICTION.
Between A. B., Plaintiff,
and
C. D., Defendant.
Reply.
The plaintiff says that-
1. As to the first paragraph of the statement of defence, he joins issue.
2. As to the second paragraph thereof, he accepts the $200 satisfaction.
The plaintiff as to the counterclaim says that-
3. The defendant waived the liquidated damages by ordering extras and material alterations in the works.
4. The defendant waived the liquidated damages by preventing the plaintiff from having access to the premises till a week after the agreed time.
(Signed.)
NOTE.-The latter part of this Form applies only where the counter-claim has been filed before the reply.
Section 174. App. E, Sec. III.
FORM No. 19.
Statement of Defence including an Objection in Point of Law.
Action No.
IN THE SUPREME COURT OF HONGKONG,
ORIGINAL JURISDICTION,
Between A. B., Plaintiff,
and
C. D., Defendant.
Statement of Defence.
The defendant
says that-
of 19
1. The goods were not supplied to E. F. on the guarantee.
2. The defendant will object that the guarantee discloses a past consideration on the face of it.
(Signed.)
Page 155
Page 156